Civil: Jury Instruction, Adverse Possession
“Plaintiff claims that he is the owner of [] because he has obtained title to…
Civil: Jury Instruction, Payment for Construction Services Rendered—EssentialFactual Elements (Bus. & Prof. Code, § 7031(a), (e))
“Plaintiff claims that Defendant owes Plaintiff money for construction services rendered. To establish this claim,…
Civil: Jury Instruction, Contractor’s Damages for Breach of Construction Contract—Inefficiency Because of Owner Conduct
“Plaintiff claims that Defendant breached the parties’ contract by delaying/disrupting/interfering with Plaintiff’s work, causing Plaintiff’s…
Civil: Jury Instruction, Contractor’s Damages for Breach of Construction Contract—Owner-Caused Delay or Acceleration
“Plaintiff claims that Defendant breached the parties’ contract by delaying/accelerating Plaintiff’s work, causingPlaintiff harm. If…
Civil: Jury Instruction, Contractor’s Damages for Abandoned ConstructionContract—Quantum Meruit Recovery
“Plaintiff claims that the parties consistently disregarded the contract’s change-order process and that the final…
Civil: Jury Instruction, Contractor’s Damages for Breach of Construction Contract—Change Orders/Extra Work—Total Cost Recovery
“Plaintiff claims that Defendant breached the parties’ contract by increasing or changing the scope of…
Civil: Jury Instruction, Owner’s Damages for Breach of Construction Contract—Failure to Complete Work
“If you decide that Plaintiff has proved his claim against Defendant for failure to complete…
Civil: Jury Instruction, Owner’s Damages for Breach of Construction Contract—Work Does Not Conform to Contract
“If you decide that Plaintiff has proved his claim against Defendant for failure to properly…
Contractor’s Claim for Compensation Due Under Contract—Substantial Performance
“Defendant claims that Plaintiff did not fully perform all of the things that he was…
Civil: Jury Instruction, Contractor’s Claim for Additional Compensation—Abandonment of Contract
“The contract between the parties provided for certain procedures to be followed if Plaintiff wanted…