“If you decide that Plaintiff has proved his claim against Defendant for failure to complete the project, you also must decide how much money will reasonably compensate Plaintiff for the harm. This compensation is called “damages.”
To recover damages, Plaintiff must prove the reasonable cost of completing the project so that it complies with the terms of the contract, including the plans and specifications, agreed to by the parties.”
[CACI Jury Instructions [citations omitted]]
